Revised gutter installation price. Total $4,185. Paid by homeowner $1,425, $700, $600 2,825. Leaving a balance of 1,860 to be paid upon completion of the job. 10% discount, leaving a balance of $1,474. TERMS & CONDITIONS 1. PAYMENT TERMS Payment for all approved additional repair work, including The remaining balance for the original gutter installation c Accepted payment methods may include cash, certified funds, 2. CHANGE ORDERS / UNFORESEEN CONDITIONS Any hidden damage, structural deficiencies, wood rot, water Additional work required due to unforeseen conditions must t Discovery of hidden damage requiring repair shall not be cor 3. RIGHT TO SUSPEND WORK Contractor reserves the right to suspend or delay work if: Payment obligations are not met Unsafe site conditions exist Additional hidden damage prevents proper installation Materials or repairs necessary to safely complete work are Any suspension caused by customer nonpayment or refusal to a 4. LATE PAYMENTS Invoices not paid within five (5) calendar days of issuance Customer agrees to pay all reasonable costs of collection, i 5. MATERIALS & WORKMANSHIP Contractor agrees to furnish labor and materials in a professional Contractor is not responsible for pre-existing structural deficiencies, concealed damage, mold, pest damage, prior improper repairs, or damage is caused by weather, events or conditions outside contractor control. 6. PROPERTY ACCESS Customer agrees to provide contractor reasonable access to t Any delays caused by restricted access, customer scheduling 7. PERMITS / CODE COMPLIANCE Unless specifically stated otherwise in writing, pricing doe Any work required solely due to existing code violations 8. LIMITATION OF LIABILITY Contractor liability shall be limited to the value to the value of services actually performed under this agreement. Contractor shall not be liable for indirect, incidental, consequential, or special damages, including loss of use, water intrusion from pre-existing conditions, or delays caused by weather, suppliers, or hidden structural defects. 9. GOVERNING LAW This agreement shall be governed by and interpreted in accordance with laws of the Commonwealth of Virginia. Any dispute arising from the agreement shall be resolved in the appropriate court of competent jurisdiction, located in Virginia. Signature ___________________ Date________________
